Terms of Service

Agreement to Terms

By accessing or using the services provided by NorthRidge Deltona Deck Builder, you agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our services or website.

Services Provided

NorthRidge Deltona Deck Builder provides professional deck construction, repair, and restoration services in Deltona, FL and surrounding areas. We offer custom design consultations, installation services, and maintenance solutions for residential properties.

All services are subject to availability and will be performed in accordance with industry standards and local building codes. We reserve the right to refuse service to anyone for any reason at any time.

Quotes and Pricing

All quotes provided by NorthRidge Deltona Deck Builder are estimates based on the information you provide. Final pricing may vary based on actual site conditions, material availability, and project scope changes. We will notify you of any significant price changes before proceeding with work.

Quotes are valid for 30 days from the date of issue. After this period, pricing may be subject to change due to material cost fluctuations or other factors.

Payment Terms

Payment terms will be specified in your service agreement. Typically, we require a deposit before work begins, with the balance due upon project completion. We accept cash, checks, and major credit cards.

Late payments may be subject to additional fees. If payment is not received according to the agreed terms, we reserve the right to place a lien on your property in accordance with Florida law.

Project Timeline

We provide estimated timelines for all projects. However, completion dates may be affected by weather conditions, material delays, permit processing times, or unforeseen site conditions. We will keep you informed of any delays and work diligently to complete your project as quickly as possible.

Warranties and Guarantees

We stand behind our work with a warranty on workmanship. Material warranties are provided by the manufacturers and vary by product. Specific warranty terms will be detailed in your service agreement.

To maintain your warranty, you must follow recommended maintenance procedures and notify us promptly of any issues. Warranty coverage does not include damage caused by misuse, neglect, or acts of nature.

Changes and Cancellations

If you need to make changes to your project after work has begun, additional charges may apply. If you cancel a project after materials have been ordered or work has started, you will be responsible for costs incurred up to that point.

Property Access and Safety

You agree to provide clear access to the work area and to secure any pets during our work hours. We will take reasonable precautions to protect your property, but you should remove valuable or fragile items from the work area before we begin.

For your safety and ours, please keep children and unauthorized persons away from the construction area during the project.

Permits and Regulations

When required, we will obtain necessary permits for your project. You are responsible for ensuring that your project complies with any homeowners association rules or deed restrictions. Additional fees may apply for permit processing.

Limitation of Liability

NorthRidge Deltona Deck Builder will not be liable for any indirect, incidental, or consequential damages arising from our services. Our total liability will not exceed the amount paid for the specific service in question.

Dispute Resolution

If a dispute arises, we encourage you to contact us directly to resolve the matter. Any legal disputes will be governed by the laws of the State of Florida and will be resolved in the courts of Volusia County.

Changes to Terms

We reserve the right to modify these Terms of Service at any time. Changes will be effective immediately upon posting to our website. Your continued use of our services constitutes acceptance of any changes.

Contact Information

If you have questions about these Terms of Service, please contact us: